The URL can be used to link to this page

394 Essx Street work specsleaptodigital.com 2.11.1 236 Cabot St· Beverly MA, 01915 978-304-0495 888-812-2783 Fax: 978-304-1928 www.mycoastalwindows.com Massachusetts License #174725 Date: 07/31/2023 Representative: Ross Rodrigue GENERAL CONTRACTOR'S AGREEMENT I/We, the owner(s) of the premises described below, hereby authorize you as a contractor to furnish all necessary materials, labor, and workmanship to install, construct, and place the improvements described herein according to the following speciﬁcations, terms and conditions on the premises described below. Customer Information Customer Name:Sarah Carter Date:07/31/2023 &/Or:Rep:07/31/2023 Address: 394 Essex St. Salem MA 01970 Contacts: Sarah: 508-335-6144 Sarah: stardustsalem333@gmail.com Siding Plank James Hardie Hardie Plank Quantity 40 Price $1,976.00 SQ Style Smooth 7.25" 6" Notes With Artisan Mitered Styled Outside Corners Color Iron Gray James Hardie Hardie Soffit Quantity 99 Price $15.60 LF Style Non-Vented Smooth 12" Color Arctic White 5" Seamless Gutters with Downspouts Quantity 99 Price $40.56 LF Color White Fascia PVC Quantity 214 Price $15.60 LF Color PVC Will Be Painted White To Look Like Painted Wood Hardie/PVC Picture Window w/ Sill Quantity 700 Price $18.72 LF Notes Band Molding and Sill Nose Color PVC To Be Painted White To Look Like Pained Wood Hardie/PVC Water Table Quantity 1 Price $40.00 LF Notes Will Be Installed Where Needed To Maintain Warranty Color Iron Grey This space intentionally left blank Page 1 of 28 leaptodigital.com 2.11.1 Louvered Shutters Quantity 11 Price $249.60 PAIR Notes Shutters Gutter Gaurds PER LN FT Quantity 99 Price $15.60 LF Disposal Fee - EVERY 20 Sq Quantity 2 Gable vents Quantity 2 Notes White Siding Permit Quantity 1 Electric Charge* Quantity 1 Siding Project Details Mounting Block Color White Dryer Vents Color White Inside Corner Color Match Outside Corner Color Match with mitered style corners Project Description Project Description Sarah’s Portion of the project. Installing all new James Hardie Smooth clapboard in Iron Grey, Arctic White solid soffiting, shutters, white 5” gutters, gutter guards, and new white Painted PVC trim in accordance with Salem Historical Comission. Labor $ Available to Promise Labor $ Available to Promise 0 It is agreed that this exhibit, along with the Siding Contract, constitutes the entire understanding between the parties, and there are no verbal understandings changing or modifying any of the terms. This exhibit may not be changed in any way unless such changes are in writing and signed by both Subcontractor(s) and Coastal Production Office. This space intentionally left blank Page 2 of 28 leaptodigital.com 2.11.1 236 Cabot St· Beverly MA, 01915 978-304-0495 888-812-2783 Fax: 978-304-1928 www.mycoastalwindows.com Exhibit WINDOW & DOOR CONTRACT Massachusetts License #174725 Date: 07/31/2023 Representative: Ross Rodrigue Customer Information Customer Name:Sarah Carter Date:07/31/2023 &/Or:Rep:07/31/2023 Address: 394 Essex St. Salem MA 01970 Contacts: Sarah: 508-335-6144 Sarah: stardustsalem333@gmail.com General Contractor's Agreement I/We, the owner(s) of the premises described below, hereby authorize you as a contractor to furnish all necessary materials, labor, and workmanship to install, construct, and place the improvements described herein according to the following speciﬁcations, terms and conditions on the premises described below. Total number of windows in the home 32 Total number of windows being installed 8 YEAR HOME BUILT 1980 EST. START DATE:Window ETA TBD EST. COMP. DATE:Window ETA TBD Windows 86-90 UI Window Style Double Hung Double Pane Price $1,944.80 Each Quantity 2 Location Living Room Window Brand Restorations Level of House First Floor Size 36 x 51 Color White Hardware Color Oil Rubbed Bronze Screen Pet screen Window Style Double Hung Details 2 Factory Mulled Units to Replace Living Room Units 55-60 UI Window Style Double Hung Double Pane Price $1,281.80 Each Quantity 1 Location Kitchen Window Brand Restorations Level of House First Floor Size 24 x 33 Color White Hardware Color Oil Rubbed Bronze Screen Pet Screen Window Style Double Hung Details Replacements For Bathroom Window Units This space intentionally left blank Page 3 of 28 leaptodigital.com 2.11.1 55-60 UI Window Style Double Hung Double Pane Price $1,281.80 Each Quantity 1 Location Master Bathroom Window Brand Restorations Level of House Second Floor Size 23 x 32 Color White Hardware Color Oil Rubbed Bronze Screen Pet Screen Glass TEMPERED Window Style Double Hung Details Windows To Replace Bathroom Unit 86-90 UI Window Style Double Hung Double Pane Price $1,944.80 Each Quantity 2 Location Master Bedroom Window Brand Restorations Level of House Second Floor Size 36 x 51 Color White Hardware Color Oil Rubbed Bronze Screen Pet Screen Window Style Double Hung Details Windows To Replace Bedroom Units Basement Hoppers Window Style Basement Sliders Awnings & Hoppers Price $1,310.40 Unit Quantity 1 Location Basement Window Brand Level of House Basement Size 30 x 15 Color White Hardware Color White Window Style Two Part Slider Details Replacement Basement Windows For Front And Rear Facing Sides Basement Sliders Window Style Basement Sliders Awnings & Hoppers Price $1,310.40 Unit Quantity 1 Location Laundry Room Window Brand Level of House Basement Size 30 x 15 Color White Hardware Color White Upgrade Dryer Vent Window Style 1/3-1/3-1/3 Three-Lite Slider Details Replacement Units For Basement Windows With Dryer Vent Under Porches Sliding Glass Doors 6' PATIO DOORS W/ OMEGA 12 Style Sliding Glass Doors Price $7,700.00 UNIT Quantity 1 Location Master Bedroom Brand Restorations SUN BLINDS ANY COLOR White Level of House Second Floor Handle Color Oil Rubbed Bronze Hardware Color Oil Rubbed Bronze Operation Hinge on the left viewed from inside Foot Lock Yes Details Sliding Patio Door To Replace Bedroom Units. Pet Screen please Construction Total 0 This space intentionally left blank Page 4 of 28 leaptodigital.com 2.11.1 Describe Scope of Work: Sarah’s windows and sliding patio door for bedroom. All windows have oil rubbed bronze hardware and pet screens. Patio door gate will be replicated in PVC to match existing. It is agreed that this exhibit, along with the Window & Door Contract, constitutes the entire understanding between the parties, and there are no verbal understandings changing or modifying any of the terms. This exhibit may not be changed in any way unless such changes are in writing and signed by both Buyer(s) and Contractor. This space intentionally left blank Page 5 of 28 leaptodigital.com 2.11.1 236 Cabot St· Beverly MA, 01915 978-304-0495 888-812-2783 Fax: 978-304-1928 www.mycoastalwindows.com Exhibit PROVIA CONTRACT Massachusetts License #174725 Date: 07/31/2023 Representative: Ross Rodrigue Customer Information Customer Name:Sarah Carter Date:07/31/2023 &/Or:Rep:07/31/2023 Address: 394 Essex St. Salem MA 01970 Contacts: Sarah: 508-335-6144 Sarah: stardustsalem333@gmail.com General Contractor's Agreement I/We, the owner(s) of the premises described below, hereby authorize you as a contractor to furnish all necessary materials, labor, and workmanship to install, construct, and place the improvements described herein according to the following speciﬁcations, terms and conditions on the premises described below. YEAR HOME BUILT 1980 EST. START DATE:Door ETA TBD EST. COMP. DATE:Door ETA TBD Describe Scope of Work: Provia Inside View Outside View Legacy Single Entry Door in FrameSaver Frame -32" x 80" Nominal Size -Unit Size: 33 9/16" x 81 11/16" -Frame Depth: 4 9/16" -2" Standard Brickmold -With Storm Door - Sized to Fit on Brickmold -Right Hand Inswing - Inside Looking Out -Entry Door -2 Panel 430 Style 20-Gauge Smooth Steel Door -ComforTech DLA -Colonial External Grid - 2V x 2H -Nightfall Inside and Outside -Hardware -Oil Rubbed Bronze Orleans Grip Handle with Deadbolt Outside -Cortina Handle Inside (2 3/8" Backset) -Frame -Nightfall Inside Frame -Bronze ZAC Auto-Adjusting Threshold (5 5/8" Depth) -Aged Bronze Ball Bearing Hinges -Security Plate Quantity 1 10390333 This space intentionally left blank Page 6 of 28 leaptodigital.com 2.11.1 Inside View Outside View Deluxe 397 Full View -32" x 80" Standard Size -Snow Mist White -Standard Z-Bar with Build-Out (Eastern) -Pre-Hung -Color Matched Piano Hinge -Hinge on Right (Viewed from Outside) -1" Color Matched Bottom Expander -Insulated Frame -Aged Bronze Windsor Handleset (DH243) -Assign a Random Key Number -Color Matched Heavy Duty Closer (DH219-01) -Standard Sash -Clear Glass -Full Screen with Heavy Duty Screen Mesh -With Screen Stabilizer Bar Quantity 1 10390333 Inside View Outside View Vantage Single Entry Door in FrameSaver Frame -36" x 80" Nominal Size -14" Sidelite Width -Unit Size: 52 13/16" x 81 11/16" -Frame Depth: 4 9/16" -2" Standard Brickmold -With Storm Door - Sized to Fit Between on the Brickmold and Mull -Left Hand Inswing - Inside Looking Out -Frame -Nightfall Inside Frame -FrameSaver Inside Mull Cover - Nightfall -Bronze ZAC Auto-Adjusting Threshold (5 5/8" Depth) -Aged Bronze Ball Bearing Hinges -No Security Plate Entry Door -006 Style Vantage Smooth Fiberglass Door -Nightfall Inside and Outside -Hardware -Oil Rubbed Bronze Orleans Grip Handle with Deadbolt Outside -Cortina Handle Inside Knob Side Sidelite -160 Style Vantage Smooth Fiberglass Sidelite -ComforTech DLA -Colonial External Grid - 0V x 4H -Nightfall Inside / Snow Mist White Outside Quantity 1 10390333 This space intentionally left blank Page 7 of 28 leaptodigital.com 2.11.1 Inside View Outside View Deluxe 397 Full View -36" x 80" Standard Size -Snow Mist White -Standard Z-Bar with Build-Out (Eastern) -Pre-Hung -Color Matched Piano Hinge -Hinge on Left (Viewed from Outside) -1" Color Matched Bottom Expander -Insulated Frame -Black Windsor Handleset (DH245) -Assign a Random Key Number -Color Matched Heavy Duty Closer (DH219-01) -Standard Sash -Clear Glass -Full Screen with Heavy Duty Screen Mesh -With Screen Stabilizer Bar Quantity 1 10390333 It is agreed that this exhibit, along with the Provia Contract, constitutes the entire understanding between the parties, and there are no verbal understandings changing or modifying any of the terms. This exhibit may not be changed in any way unless such changes are in writing and signed by both Buyer(s) and Contractor. This space intentionally left blank Page 8 of 28 leaptodigital.com 2.11.1 236 Cabot St· Beverly MA, 01915 978-304-0495 888-812-2783 Fax: 978-304-1928 www.mycoastalwindows.com Exhibit ROOFING CONTRACT Massachusetts License #174725 Date: 07/31/2023 Representative: Ross Rodrigue GENERAL CONTRACTOR'S AGREEMENT I/We, the owner(s) of the premises described below, hereby authorize you as a contractor to furnish all necessary materials, labor, and workmanship to install, construct, and place the improvements described herein according to the following speciﬁcations, terms and conditions on the premises described below. Customer Information Customer Name:Sarah Carter Date:07/31/2023 &/Or:Rep:07/31/2023 Address: 394 Essex St. Salem MA 01970 Contacts: Sarah: 508-335-6144 Sarah: stardustsalem333@gmail.com Locations INCLUDED in scope of work to be performed Basement entry bump out roof. Locations EXCLUDED in scope of work to be performed Rest of the home Job Speciﬁcation Shingle Style GAF Timberline HD-Z Quantity:1 Color Charcoal Price $988.00 SQ It is agreed that this exhibit, along with the Rooﬁng Contract, constitutes the entire understanding between the parties, and there are no verbal understandings changing or modifying any of the terms. This exhibit may not be changed in any way unless such changes are in writing and signed by both Buyer(s) and Contractor. Sarah Carter 07/31/2023 Date Ross Rodrigue 07/31/2023 Date This space intentionally left blank Page 9 of 28 leaptodigital.com 2.11.1 Addendum 236 Cabot St· Beverly MA, 01915 978-304-0495 • 888-812-2783 • Fax: 978-304-1928 This form represents additional work to be performed by Coastal Windows & Exteriors over and above what is speciﬁed in the original contract. Home as a construction site: Your home will be a construction site during the installation of your products and it will be noisy. There may be a signiﬁcant amount of job debris associated with your project installation, most of which will be cleaned up and removed at the end of each day, and upon job completion. However, it is possible some nails or debris may be missed during the site cleanup. We recommend the homeowner use caution when walking around the construction site (especially children and pets) to avoid possible injury. Rotten or Deteriorated Wood: The exact condition of your existing products cannot be veriﬁed until we remove your products, if applicable. If rotten or deteriorated wood is discovered AFTER removing your existing products, additional charges will apply. Repairs to your home may conﬂict with the original (estimated) completion date. Coastal Windows & Exteriors has your approval to replace or repair any damage found, at an additional cost (Approximate cost, labor and materials necessary for re-sheeting/new sheeting will be $755 per square) Setup/Job Access: Coastal Windows & Exteriors has your approval to access the driveway for delivery of the products and dump truck (if applicable). If homeowner chooses not to assume liability for the consequences of having equipment access the property, there may be additional cost. Please let us know where you would like us to stage your materials (where to place the materials, dumpster, park vehicles, and where to store our equipment). Keep in mind that everything we use needs to be as close to the house as possible, and our workers need access to a grounded electrical source in order to run their equipment. Please insure all pets and animals are properly secured. We will attempt to protect the surface of your driveway, although minor scratches or cracks may occur. Please notify us prior to starting the job if you have a sprinkler system, septic ﬁeld or well, and if so the location(s). Cleanup: At Coastal Windows & Exteriors, cleanup is important. We will remove and dispose of all product/project debris. Any other sensitive or valuable items stored on house and garage walls must be removed by customer prior to and during installation of siding. Plants & Shrubbery: During the installation process some damage may occur to the surrounding plants and shrubbery. Coastal Windows & Exteriors will take every precaution to protect plants / shrubbery, however their replacement is not included in this proposal. and bushes at least two feet from the house. If customer hasn’t trimmed shrubbery by the time work has started, contractor has permission to trim back shrubbery feet from the house at the regular labor rate. Security Alarms: Customer is responsible for coordinating work with Customer’s home security program. Coastal Windows & Exteriors is not responsible for disconnecting or reconnecting any part of client’s alarm system. If Coastal Windows & Exteriors disconnects any part or component of alarm system, Coastal Windows & Exteriors assumes no responsibility for the alarm’s working condition. Electrical & Solar Work: Coastal Windows & Exteriors is responsible for unmounting and remounting the electrical meters, existing lighting and hookups on your home. Any additional electrical work added to the project will be the responsibility of the homeowner to be paid upon completion of the project. These charges cannot be added to ﬁnancing plans. This includes but not limited to solar inverters, moving lighting ﬁxtures, doorbells and bringing the home up to code. INSURANCE: All work in the following proposal is covered by the appropriate insurance and local and state licensing required by law. To complete jobs in a timely manner, Coastal Windows & Exteriors will use factory trained independent subcontractors at its discretion for all or part of the construction replacement of Rooﬁng, Siding, Windows, Gutters, and Doors. All independent subcontractors used for any contract will be held to the quality standards of the product manufacturer and will hold and maintain appropriate insurance and license coverage. This space intentionally left blank Page 10 of 28 leaptodigital.com 2.11.1 PETS: Please keep all pets out of the install work area. Company is not responsible for injuries to pets if they occur during our installation. We want your pets to stay safe. WEATHER: Coastal Windows & Exteriors will not install in any weather that may cause damage to your home or the materials being installed. Coastal Windows & Exteriors holds the right to install at their discretion. We cannot install in heavy rainfall or when the weather is overly hot because the temperature can ruin materials. We will not install during inclement weather that may cause a safety hazard. ALL PRODUCTS- Payment with Work Left to be Done: At the completion of your project, there may be one or two items left to be completed. For example, there may be a scratch on one window (possibly requiring a reorder), or a screen may be damaged, etc. In these cases, substantial payment is required with a reasonable portion being held back until completion. Another example: If your project is for twelve windows and the installation is complete, but one window is damaged, we would require payment on the eleven windows, and a hold payment on the twelfth, until it is installed properly. Again, the expectation is one of common sense and fairness. If you are ﬁnancing your project through a lender and your project is substantially complete you will be required to sign the bank’s completion certiﬁcate. WINDOWS-Reverse Condensation: Your new windows are considered “Super Insulated” windows. This means that from this point forward, your home will lose very little heat through its windows. Since the windows will no longer be warm on the outside, it is not uncommon for dew to form on the exterior surface of the glass in the early morning hours, just as it forms on your car or your lawn. This is a normal occurrence for this product and is a sign of its remarkable insulating capabilities...this dew typically disappears by mid-morning. WINDOWS-Window Treatments and Air Conditioners: Because replacement windows ﬁt within your existing frames and reduce the overall size, the installation of your windows can sometimes cause existing window treatments (blinds, drapes, shades, etc.) and air conditioners to no longer ﬁt, and require alteration or replacement. Please ask your representative to explain this to you, and to examine your particular window openings to see how this may affect you. Coastal Windows & Exteriors assumes no responsibility for the cost, or the labor involved, with reﬁtting window treatments and/or air conditioners. Please remove blinds and curtains and A/C units from window opening prior to install date and have furniture moved back at least 3 feet. WINDOWS/DOORS-Trim Work: The installation of your windows or doors may require the installation of some interior wood- trim. If that is the case, the trim work is left as ﬁnished carpentry, ready to paint. Coastal Windows & Exteriors does not do any painting or staining. Preparation (Tear Off): Coastal Windows & Exteriors will tear off existing product material and dispose of. If hidden layers are found, they will be removed at an additional [tearoff] per square, per layer. Satellite Dish: Coastal Windows & Exteriors will remove existing satellite dish from the home. It is recommended that customers have the appropriate satellite company reinstall it. Due to technical considerations Coastal Windows & Exteriors is not responsible for alignment of dish to satellite. FLASHING, SIDING, GUTTERS & GUTTER COVERS: Step ﬂashing and roof to wall ﬂashing provides a watertight transition between rooﬁng, materials, walls, skylights, and chimneys. To ensure a quality and proper install, Coastal Windows & Exteriors may have to replace the ﬂashing or cut back the siding and/or gutters to get new ﬂashing in place. While Coastal Windows & Exteriors does its best to not damage any existing siding and/or gutters, sometimes the siding and gutters do not cooperate and may need some minor repair or paint. Debris from the roof removal can also cause damage to other exterior parts of the home. Coastal Windows & Exteriors is not responsible for any damage caused by debris from roof removal, nor any siding, gutter, and/or gutter cover repairs or painting. Remove All Items from Interior Walls: Please remove pictures, mirrors and other items that are not securely attached to the wall areas inside the home. This includes items such as plates displayed on a plate rail and fragile items on open shelves. When old product is removed or new product is nailed, occasionally “nail pops” (raised nail heads) may emerge. If this occurs, we will not be responsible for patching, painting or wallpapering interior walls. NAILS THROUGH SOFFIT & IN ATTIC: VIA the GAF warranty and code, Coastal Windows & Exteriors is required to use nails to adequately install your shingles. These nails will come through your soffit material and into your attic. Coastal Windows & Exteriors is not responsible for any damage or painting that these nails may cause. This space intentionally left blank Page 11 of 28 leaptodigital.com 2.11.1 UNDER ROOF DECK/IN ATTIC: Coastal Windows & Exteriors is not responsible for any repairs or replacement of any materials underneath the roof decking or inside the attic. {Example: not responsible for exhaust vents; connecting them and/ or replacing.} SKYLIGHT: Coastal Windows & Exteriors will properly ﬂash your skylight but is not responsible for any interior ﬁnish work including trim, sheetrock or paint repair. MATERIAL IN ATTIC: To install the venting system Coastal Windows & Exteriors will be cutting into the ridge of your home, this may cause debris to fall into your attic. Your estimate does not include covering your belongings or removing any small debris that may fall into your attic during the install process. If you have belongings stored in your attic you may want to cover or remove them. All agreements must be in writing. Verbal agreements made with the representative or any employee will not be valid. Normal Work Hours may vary by project location and season but should fall between the hours of 8AM and 8PM Monday- Friday. (Work may occasionally be done on weekends depending upon installer availability). Acceptance of Proposal - The above or attached prices, speciﬁcations and conditions are satisfactory and are hereby accepted. You are authorized to do the work as speciﬁed. Sarah Carter 07/31/2023 Date This space intentionally left blank Page 12 of 28 leaptodigital.com 2.11.1 SAMPLE PRE-RENOVATION FORM SAMPLE PRE-RENOVATION FORM This sample form may be used by renovation ﬁrms to document compliance with the Federal pre-renovation education and renovation, repair, and painting regulations. Occupant Conﬁrmation Pamphlet Receipt ✅ I have received a copy of the lead hazard information pamphlet informing me of the potential risk of the lead hazard exposure from renovation activity to be performed in my dwelling unit. I received this pamphlet before the work began. Owner-occupant: Sarah Carter 07/31/2023 Date Renovator’s Self Certiﬁcation Option (for tenant-occupied dwellings only) Instructions to Renovator: If the lead hazard information pamphlet was delivered but a tenant signature was not obtainable, you may check the appropriate box below. " Declined – I certify that I have made a good faith effort to deliver the lead hazard information pamphlet " Unavailable for signature – I certify that I have made a good faith effort to deliver the lead hazard information pamphlet to the rental dwelling unit listed below and that the occupant was unavailable to sign the conﬁrmation of receipt. I further certify that I have left a copy of the pamphlet at the unit by sliding it under the door or by (ﬁll in how pamphlet was left). Person Certifying Delivery Ross Rodrigue 07/31/2023 Date Unit Address 394 Essex St. Salem MA 01970 Note Regarding Mailing Option — As an alternative to delivery in person, you may mail the lead hazard information pamphlet to the owner and/or tenant. Pamphlet must be mailed at least seven days before renovation. Mailing must be documented by a certiﬁcate of mailing from the post office. Page 13 of 28 leaptodigital.com 2.11.1 Customer Information Sarah Carter 394 Essex St. Salem MA 01970 Sarah: 508-335-6144 Sarah: stardustsalem333@gmail.com Date: 07/31/2023 Rep: Ross Rodrigue Homeowner's Association NO NOTICE: The Signature of the parties above apply only to the Contract of the parties to alternative dispute resolution initiated by the Contractor. The homeowner may initiate alternative dispute resolution even where this section is not separately signed by the parties. No work shall begin prior to the signing of this Contract and transmittal to the Homeowner of a copy of the Contract.This contract constitutes the parties' total agreement This contract may be amended or supplemented only by a written change order signed by the owner and contractor. All surplus material is property of COASTAL WINDOWS & EXTERIORS. You agree to be bound by general conditions of the reverse side. The Homeowner has seen "sample"warranties that will be provided by COASTAL WINDOWS & EXTERIORS upon installation. NO ORAL AGREEMENTS ARE ACCEPTED! (Customer's Initials) You, the buyer, may cancel this transaction at any time prior to midnight of the third business day after the date of this transaction. See Notice of Cancellation form provided to you herewith for an explanation of this right. IN WITNESS WHEREOF, the parties have hereunto signed their names this Monday 07 31 of 2023. Any deposit required under this Agreement to be paid in advance of the commencement of work shall not exceed the greater of one-third of the total contract price or the actual cost of any materials or equipment of a special order or custom-made nature, which must be ordered in advance of the commencement of work, in order to assure that the project will proceed on schedule. No ﬁnal payment shall be demanded until the contract is completed to the satisfaction of the parties. Windows & Sliding Glass Doors Total $20,664 James Hardie Siding Total $109,711 Rooﬁng Total $988 Provia Total $19,832 Total Contract Amount $54,537 Deposit Form of Payment Check Deposit $5,454 Due Upon Material Delivery Form of Payment Due Upon Material Delivery $0 Due Upon Job Completion $49,083 Financing Details Amount Financed $49,083.00 Estimated Monthly Payment $540.40 SALAL 11.99 @ 240 Months $0 fee FINANCING IS SUBJECT TO CREDIT APPROVAL Additional Details Our ﬁnance manager will reach out once you complete your credit application and review the payment plan and options. This space intentionally left blank Page 14 of 28 leaptodigital.com 2.11.1 Sarah Carter 07/31/2023 Date Ross Rodrigue 07/31/2023 Date -This agreement is subject to ﬁnancing which you must secure within thirty (30) days after the date of this agreement. If Financing acceptable to Coastal Windows & Exteriors is not obtained within 30 days, this agreement may be cancelled by either party. All home improvement contractors and subcontractors must be registered by the Chief Administration of the Massachusetts Board of Building Regulations and Standards. Any Inquiries about a contractor or subcontractor relating to registration should be directed to: Director of Home Improvement Contractor Registration, One Ashurton Place, Room 1301, Boston, MA 02180, (617) 727-8598 The Contractor shall obtain and pay for the building permit and other permits and governmental fees, licenses and inspections necessary for proper execution and completion of the Work. If the Homeowner elects to obtain forgoing permits, or deal with unregistered contractors, the Homeowner will be excluded from the guaranty provisions of M.G.L.c. 142A.The Homeowner shall obtain and pay for all other necessary approvals, easements, assessments and charges. The Contractor and homeowner hereby mutually agree in advance that in the event the Contractor has a dispute concerning this Contract, the Contractor may submit the such arbitration as provided in Massachusetts General Laws, Chapter 142A. This space intentionally left blank Page 15 of 28 leaptodigital.com 2.11.1 General Conditions 1. BUILDING CODES A. The Contractor shall complete the work as speciﬁed. In the event that the building department or other government agency subsequently requires work to be performed by the Contractor which is not speciﬁed in this Agreement, or in the event that the Contractor uncovers or discovers defects or problems in the existing structure which should be corrected to conform to safety requirements or standard construction practices, the Contractor will advise the Customer of any changes in the required work and proceed to perform such change s pursuant to Section 4 of this Agreement. B. The Contractor is not responsible for any special inspections, analyses or reports that are not ordinarily provided for the building inspector. 2. RIGHT TO SUBCONTRACT. Contractor has the right to subcontract any part of the work which Contractor is not capable of performing itself due to non- availability of qualiﬁed labor or materials, or unexpected conditions. 3. CONTRACTORS RIGHT TO LIEN. Contractor has the right to a lien on the real property described in this Agreement to secure payment. This lien may be enforced by foreclosure and sale of the property if amounts payable to the Contractor under this Agreement are not paid when due. 4. CORRECTION OR COMPLETION OF WORK. A. The contractor shall have the ﬁrst right to perform all corrective work, unless the Contractor declines to do so following receipt from the Customer of a punch list together with a reasonable period of time within which to perform the work. The Customer shall not offset the cost of completing any work stated on the punch list against any balance owed to the Contractor, nor shall the Customer contract with any alternative contractor for the performance or completion of work within the scope of this Agreement unless the Contractor shall have been ﬁrst provided with written notice of the opportunity stated above. B. Customer shall pay Contractor any amounts withheld from ﬁnal payment within three days of the Contractor's completion or correction of work identiﬁed on the Customer's punch list. 5. CHANGES IN THE WORK A . The Customer may request change orders after commencement of construction . Such request shall be made directly to the Contractor, and not to subcontractors or employees of subcontractors. Change orders should be reduced to a signed writing in order to avoid misunderstandings over cost or scope of the change order. A written change order will be on a form prepared by the Contract or and shall state the effect of the change order upon the contract price. B. Unless otherwise agreed by both parties in writing , all extra work and change orders performed by Contractor shall be billed by Contractor and paid by the Customer at the rate of $136.00 per man hour for all labor, plus 15%markup on all invoiced materials, subcontractors, equipment, and permits. C. Upon substantial completion of the work, you agree to promptly execute and deliver to Contractor a properly completed certiﬁcate of completion in a form satisfactory to Contractor attesting to completion of the work. 6. FINANCING. If you obtain ﬁnancing but your ﬁnancing is subsequently revoked, rescinded, or your ﬁnancer fails to pay Contractor the balance due under the contract for any reason, you must pay Contractor the contract price for all completed work. 7. INTEREST. Any amount owed under this Agreement, regardless of whether the amount in dispute is liquidated or unliquidated, shall bear interest at 18% per annum or the legally maximum rate, whichever is less, from the date of the initial invoice. 8. LIQUIDATED DAMAGES CLAUSE. After you have signed this Agreement and any applicable right of cancellation has expired, if you withdraw your authorization for, or refuse to allow, COASTAL WINDOWS & EXTERIORS to perform the work as speciﬁed for the price as speciﬁed pursuant to the terms of this Agreement, then COASTAL WINDOWS & EXTERIORS, at its sol e and exclusive option, may elect to claim and collect liquidated damages from you. The amount of liquidated damages shall equal 33% of the total due, including tax, or the cost to COASTAL WINDOWS & EXTERIORS up to the date of the withdrawal of your authorization , whichever is greater. These liquidated damages are agreed to as a reasonable assessment and anticipation of the actual damages that will be sustained by COASTAL WINDOWS & EXTERIORS in the event that you withdraw your authorization for, or refuse to allow , COASTAL WINDOWS & EXTERIORS to complete the work as speciﬁed in this Agreement. 9. DELAY/UNKNOWN CONDITIONS: I understand that if Contractor determines within sixty (60) days of the date of this Agreement that it cannot perform the work according to Contractor's professional standards, Contractor can cancel this Agreement, notify me of cancellation, and promptly return my money. I understand that issues that may cause Contractor to cancel this Agreement would be incorrect pricing or unknown pre-existing conditions to my property. I understand that Contractor is not responsible for structural or other defects in my property, and that Contractor' s products do not cure these problem s. I also understand that the work could be delayed by events that Contractor does not control, and that is acceptable to me. Some of the things that could cause the work to be delayed would be acts of God, labor strikes, inclement weather, material shortages, my inability to qualify for or obtain ﬁnancing I need to pay for the work, or delays by local government authorities in issuing or approving inspections, permitting, or other required authorizations for the work. When Money Is Due: I agree that when the work is "substantially complete", I will pay Contractor the balance due on the purchase price. I understand that substantially complete · means the work has been materially ﬁnished, functional as intended, and a ﬁnal walk through with a contract or, permit , or occupancy certiﬁcate, if required, has been obtained. I agree that once I have paid the entire purchase price, if I believe any of the work performed by Contractor is defective or incomplete, Contractor will inspect the work and will perform any service I am entitled to under this Agreement and/or any warranty. I agree that if I do not pay the Contractor any of the money owed when it is due, I can be charged a late fee of 1.5% on the amount owed for each month the money is owed and not paid. I also agree that if I default on my promises under this Agreement, and the Contractor hires an attorney to enforce this Agreement, I will pay the Contractor its reasonable legal fees and related costs or expenses, as long as it is legal for me to do that. 10. SERVICE CHARGE: Non-warranty calls for repair or adjustment will result in a $200 trip fee, plus $120 per hour, not including the cost of materials. 11. WARRANTY, LIMITATIONS OF LABILITY. The products which are the subject of this Agreement may be covered by a limited warranty issued by the manufacturer. See the manufacturer's warranty for details. The manufacturer 's warranty is the sole and exclusive warranty with respect to the product s. COASTAL WINDOWS & EXTERIORS' RESPONSIBILITY AND LIABILITY IS LIMITED TO REPAIR OR REPLACEMENT OF DEFECTIVE INSTALLATION WORK. COASTAL WINDOWS & EXTERIORS INSTALLATION WARRANTY EXPIRES ONE YEAR AFTER INSTAL LATION. THERE ARE NO OTHER WARRANTIES, EXPRESS OR IMPLIED. UNDER NO CIRCUMSTANCES SHALL COASTAL WINDOWS & EXTERIORS BE LIABLE FOR CONSEQUENTIAL DAMAGES, OR ANY DAMAGE CAUSED BY MISUSE, ABUSE, OR ACTS OF NATURE, INCLUDING FIRE, FLOOD, OR EARTHQUAKE. This space intentionally left blank Page 16 of 28 leaptodigital.com 2.11.1 Sarah Carter 07/31/2023 Date Ross Rodrigue 07/31/2023 Date This space intentionally left blank Page 17 of 28 leaptodigital.com 2.11.1 236 Cabot St· Beverly MA, 01915 978-304-0495 • 888-812-2783 • Fax: 978-304-1928 www.mycoastalwindows.com Massachusetts License #174725 Date: 07/31/2023 Representative: Ross Rodrigue Sarah Carter 394 Essex St. Salem MA 01970 Sarah: 508-335-6144 Sarah: stardustsalem333@gmail.com Date: 07/31/2023 Rep: Ross Rodrigue NOTICE OF CANCELLATION Date of Transaction:07/31/2023 You may CANCEL this transaction, without any Penalty or Obligation, within THREE BUSINESS DAYS from the above date. If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within TEN BUSINESS DAYS following receipt by the seller of your Notice of Cancellation, and any security interest arising out of the transaction will be cancelled. If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the seller's expense and risk. If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your Notice of Cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract. To cancel this transaction, mail, fax, or deliver a signed and dated copy of this Notice of Cancellation or any other written notice, or send a telegram to: NO LATER THAN MIDNIGHT OF 07/03/2023 Sarah Carter 07/31/2023 Date This space intentionally left blank Page 18 of 28 leaptodigital.com 2.11.1 Page 19 of 28 leaptodigital.com 2.11.1 Page 20 of 28 leaptodigital.com 2.11.1 Page 21 of 28 leaptodigital.com 2.11.1 Page 22 of 28 leaptodigital.com 2.11.1 Page 23 of 28 leaptodigital.com 2.11.1 Page 24 of 28 leaptodigital.com 2.11.1 Page 25 of 28 leaptodigital.com 2.11.1 Page 26 of 28 leaptodigital.com 2.11.1 Page 27 of 28 leaptodigital.com 2.11.1 Page 28 of 28