8 SKERRY ST - BUILDING INSPECTION 143%"Sld"STIE f4UE 41 APMOVED BY T44E
1WZCIDB PAIDR TL)A_PERTT S,EWG GRANTED
CITY OF SALEM
No. 3:; \° Date d S
Is Property Located In Location of
the Historic District? Yes_No !!!_��� gnu
Is Property Located in /
Me Conservation Area? Yes No 1G
BUILDING PERMIT APPLICATION FOR:
Permit to:
(Circle whichever apply)CRioc600f, Install Siding, Construct Deck, Shed, Pool,
epair/Replace, Other:
PLEASE FILL OUT LEGIBLY&COMPLETELY TO AVOID DELAYS IN PROCESSING
TO THE INSPECTOR OF BUILDINGS:
The undersigned hereby applies for a permit to build according to the following
specifications:
Owner's Name
Address & Phone rIt
Architect's Name
Address & Phone ( )
Mechanics Name S Z�
Address & Phone a z
What is the purpose of building?
Material of brdkkV? It a dwelling, for how many families?
Will building conform to law? Asbestos?
Estimated Iasi v L o 6zity License o !v A state #
HMO Imp nt
/ Lie. / 3
n ure of Applicant
SIGNED UNDER THE PENAL
OF PERJURY
DESCRIPTION OF WORK TO BE DONE
cc ce- foz-)�
MAIL PERMIT TO: box fC7i�
Nq.
APPLICATION FOR
PERMIT TO
LOCATION
PERMIT GRANTED
APRROVV/fD
ECTOR OF UIL� DINGS
r
0'/' e ,'P' ���5✓'���1 'L� 'u+'�%P "
J TTzz hoard of 13uildi»g R gulatt()ns and Standacc s
,l
One Ashburton Place - R001`11 130I
ra ,
Boston. Massachusetts 02108
istration
ovenlent Contractor Red, .
Rome Inwr
- Registrations. 137193
TVpe� SUPOlement Card
rxpiration 10/1512006
BAY STATE ROOFER INC. —
ROBERT O'KEEFE _ --
PO BOX 189 MA
Llpdatehddress and i "all gird Rf �rh rcaaon ford)
st Card
N. READING, Address I] Reuewnl On mplogm m t
r`
G/�z �ni rin nz"o�za l/r r�'�� rA«r�rr�all�
[3oird or Bndd&a Rcmulaunua aad 5lmdarAs before We exp "lion ndateh�tl(rtoundil return Loony
tF ��.,1 HOME IMPROVEMENT CONTRACTOR
Bo,rd of F3uildmg Regu la lions and Standards
1 1 I i 71i1 One,Ashbi 'ton Place Rm 1301
r ;7 Registration: 137193
r Expiration: 1011512006 l3ostou.Tr a. 2100
Type: Supplement Card
BAY STATE ROOFER INC.
ROBERT O'KC EFI°. ._—.--------
240PARK ST. C`.! r�i _ 0\0
—t� without s�gnatI c
N. READING, 10A 01664 _ Admi'list:rtnr
Bay State Roofers, Inc.
P.O. Box 189
North Reading, Massachusetts 01864
978-664-0668
MAILING ADDRESS:
Cydy Plouff � (
8 Skerry Street
Salem, MA
July 14, 2005
RE: New Shingle Roof
DeaFCyridy,
Bay State Roofers Inc.; proposes to furnish all materials, labor and equipment necessary to perform the following scope
of work:
1. Remove approximately 1700 square feet of the existing asphalt shingle roof down to the wood decking.
2. Install new ice and water shield along the 3' roof edge and around all the roof penetrations.
3. Install new 15 lb felt paper throughout the roof area.
4. Install new white aluminum drip edge along the roof perimeter.
5. A new 30 —year GAF Architectural asphalt shingle will be installed over the prepared substrate.
6. A new ridge vent will be installed to ensure the proper roof ventilation.
7. All roof penetrations and flashing will be installed according to the manufacturers recommended specifications and
details.
8. Bay State Roofers, Inc. will properly dispose of all roof debris in our own waste containers.
Total Price for this work: $6,000.00 Deposit: $2,000.00
Add additional $380.00 to install new lead flashing on both chimneys.
Add additional $120.00 to cover flat roofs with ice and water shield.
Note: Any wood decking that needs replacement will be an additional $2.50 per square foot.
Authorized Signature:
Waste containers supplied by Bay State Roofers, Inc.are for the sole purpose of roof debris.
Under no circumstance, is the homeowner to use these containers for personal refuse
CONTRACT ACCEPTANCE
The specifications,prices,payment schedule and attached Date: U
Conditions are satisfactory and hereby accepted. BAY
STATE ROOFERS, INC.Is authorized to perform work Signature:
as specified Payment will he made as previously outlined.
NpTE. Unpaid bills over 30 days aree subject to l 12%(nance charge per month(I B%annual) Title:
f
PROVISIONS OF THE AGREEMENT
L PROJECT PROVISIONS e. Damage to Project:Contractor will not be responsible for any
a. Guideline:The Project wifl be constricted in strict conformance damage caused by the Owner,or other causes beyond the control of
to the plans and specifications which have been examined and the Contractor.Owner will pay for any restoration work.
approved by the Owner. W.CONTRACTOR'S RIGHTS AND RESPONSIBILITIES
b. Compliance:The Project will be completed in strict compliance a. Delay: Contractor will be excused for any delay beyond his
with all laws, ordinances, rules and regulations of the applicable reasonable control. These delays may include, but are.not limited to
government authorities. Acts of God,labor disputes,inclement weather,acts of public authority,
c. Control:The Agreement plans and specifications ate intended acts of the Owner,or other unforeseen contingencies.
to supplement.each other.In case of conflict the plans will control the - b. Right to Stop Work:If any payment under this Agreement is
specifications and the Agreement provisions will control both. not made when due,the Contractor may suspend work on the job until
d. Charge Orders:As directed by the Owner,construction tender, such time as all payments due have been made.Any failure to make
public body a§spedor,anyatImbonOr deviation from tie specifications payment is subject to a claim enforced against the property in
that involves extra cost(subcontract:labor,materials)will be executed accordance with the applicable Pen laws.
only upon the parties entering into a written change order. Expense c. Substitution of Materials:Contractor may substitute materials
Incurred because of unusual or unanticipated conditions will be paid for 'without notice to the Owner in order to allow work to proceed,provided
by the Owner. that the substituted materials are of no lesser quality than Lose listed
e. Allowances. if the Agreement price includes allowances,and in the specifications.
the cost of performing the work is greater or less than this allowance, d.Salvage:All salvage resulting from work under this Agreement
then the Agreement price wilt be adjusted accordingly. is to be retained by the Contractor unless other agreements are
It.FINANCIAL RIGHTS AND RESPONSIBILITIES - contained in the written Specifications.
a. Labor and Material: Contractor.will provide and pay for all e. Insurance: Contractor will maintain workers' disability
labor and materials necessary to complete the Project. Contractor is compensation insurance for his employees and comprehensive public
released from this obligation for expenses incurred when the Owner is liability insurance policies.
in arrears in making progress payments. V.COMPLETION OF PROJECT
b. Permits:Contractor will obtain and pay for all required building a. Notice: Owner agrees to sign a Notice of Completion within 5
permits and licenses. days after completion of the project. If project passes final inspection
C. Taxes,Assessments and Charges:Taxes,speclat assessments and the Owner does not sign the Notice,the Contractor may act as the
of all descriptions, and charges required by public bodies and utilities Owner's agent and sign the Notice.
will be paid for by the Owner. b. Clean-up: Contractor is responsible for removing debris and
d. Deposit of Payments: Contractor is required to deposit all surplus material from the property, and leaving the property in a neat
payments received prior to completion in an escrow account. In lieu of and orderly condition.
such a deposit,the Contractor may post a bond or contract of indemnity VI.CONFLICT PROVISIONS
with the Owner guaranteeing the return or proper application of such a. Arbitration: Any controversy or claim arising out of this
payments to the purposes of the contract.All advanced funds will be Agreement that cannot be resolved, is subject to arbitration,with
deposited as indicated under Special Provisions. Monies used in _ an arbitrator of mutual agreement, and all parties (including
escrow become the property of the Contractor when they are applied Owner, Contractor, Architect and Sub-Contractors) are bound to
according to the Agreement payment schedule, when a breach of this arbitration: It any party does.not appear at arbitration
contract by the Owner occurs, or when the Agreement has been proceedings,the arbitrator is empowered to decide the controversy
substantially performed in accordance with whatever evidence is presented by the
e. Bankruptcy: If either party becomes bankrupt,the other party party(ies)that do participate.
has the right to cancel this Agreement. b. Attorney Fees:If either parry becomes involved in litigation
III.OWNER'S RIGHTS AND RESPONSIBILITIES arising out of Agreement, the Court shall award costs/expenses
a. Cancellation: Owner has an unconditional right to cancel the including attorney fees to the party justly entitled to them.
Agreement, without penalty or obligation, until midnight of the third c. Limitations:No action related to this Project may be made
business day after the Agreement was signed. Cancellation must be by either party against the.other more than 2 years after the
done in writing. Upon cancellation, any property traded in, any completion of work.
payments made under this Agreement.and any negotiated instrument VII. GENERAL PROVISIONS
executed will be returned within 10 business days following receipt by
the Contractor of cancellation notice. a. Notice:Any notice required or permitted under this Agreement
b. Property Lines: Owner shall locate and point out property may be given by certified or registered mail at the addresses contained
in the Agreement.
fines to the Contractor.Contractor may,at his option,require the Owner
to provide a licensed land surveyor's map of the property. U. Prohibition of Assignment: Neither parry may assign this
c. Liens: Failure to pay persons supplying materials or services Agreement or payment due under this Agreement without the written
consent of the other parry.
according to the terns of this Agreement may result in the filing of
mechanic's liens on the affected property. Owner has the right to ask c. Gualification:This document constitutes the entire agreement
the Contractor for lien waivers from all persons supplying these of the parties. No other agreements exist. This Agreement can be
materials or services. In the event any mechanic's lien is filed through modified only by written agreement signed by both parties.
no fault of the Owner, then the Contractor agrees to take all steps d. Governance:This Agreement shall be construed in accordance
necessary for the release and discharge of such lien. with and governed by, he laws of the state in which the Project is
d. Insurance:Owner will maintain property damage insurance at located.
least equal to the Agreement price.
CERTIFICATE OF INSURANCE ISSUE DATE
o^io�i�oo PRODUCER TIIIS CERTR ICATE I ;ISSUED AS A DIAI TER OF INF'OE-NIATION ON'i,Y AND
Brewer $. Lord LLC CONFERS NO RIGHTS UPON THE CERTIFICATE IiOI,DER. THiS CERTiFICATF
DOF,S NOT An4FN,),FRTEND OR ALTER THE COVERAGE AFFORDED IIS"1'HE
P O Box 9146 POLICIFs BFLOI}-.
Norwell, MA 02061 COMIPANIES AFFORDING COVERAGE
INSURED
Bav State Roofers Inc
COMPANY P O BOX 189 LETTER A A.I.M. Mutual Insurance Co
North Reading, MA 01864
COVERAGES__
THIS IS I CERTIFYfEA]'THE POLICIES OF TNSURANCE LISTED BELOW FI9VE BF..EN ISSUED TO THE INSURED N AMED ABOVE FOR THE POLICY Pl.P
INDICATED.NOTWITHSTANDING ANY REQUIREMENT,'TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RE$PEGTTO WHIC'II LI
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE. Tf.P\,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAMS.
("O ' ' B OF INDANG POLICYEFFEC'FIVE POLICY EXPIRATION LIR (S R DdrF(MM/DD/YY) pATFAI,A/ D/YY)I —
LWITS
6ENF,R:\I.LIABILITY GFN'ERAL AGGREGATE —I. S
�COMMERCIALGENERALLI,\RiLITY PRODUCTS-COMPIOP AGG, S
JCLAINISMADEF—EOCCIJkI -- --- _
PERSONAL&ADV.INJUR}' S
OWNER'S&CONTRACTOR'b rRo'r, EACIi�'CE - 5
'—' -- FIREDA,\IAGF(Anyonufirc) 1 S
M F-D.EXPENSE(Any unc PCrsmi) S
AUT031OBILE LIABILITY _
I COMIJINF,p SINGLE I S
1 —],wrnuro LIMrr 1
\LL OWNED AUTOS T- -- --
SCHEDULED AUTOS BODILY IN'J1JRY� � S
(Per Perton)
JHIRGD AUTOS _
�
BODILY INJURY
NON OWNED AII'r0$ � � I(Rra¢idenp � S
GARAGE LIABII_ITl'
PROPERTYDA.}IAGE I S ---
-CCESS LIABILITY
—I (EACH OCCURRENCE S
LI bIBRLLL A FOR41 I I — ---___
IAGGNI GAII y
�'OTHER 9HAS UMBRELLA FOK.\1
\'ORhFRS GDM1IPI\NATION ANII o'Lsra 1'PrOrzl' IX 0[HER
31 PLOY EA$'LIABILITY nui _
A 6008315012005 04/03/2005 - 04/03/2006 IFL EACH ACCIDENT 'S 50000(I -
INIEIROPRIETOW I,SCL _PAR'TUERS/ExEculkF I--- El- SE PoucYu}IIT� s _500 0011
oTIIER
OTFIER `_ARE: X BXCL. LDISLASE—EACH 1-WLOVEF S 5(]n 000� � _ .
DF,SCRIPITON OF OPERATIONSILOCAI JONSIVEI IICLESISPECL\L ITFili s — -.
I
I
CERTIFICATE HOLDER CANCELLATION —i
SHOULD ANY OF"IHE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORU: !IQ
BAY STATE ROOFERS, INC. - EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TU �
MAIL 10 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO'I f[E.
LEFT. BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION' OR ;
240 PARK STREET LIABILITY OF ANY KIND UPON THE COMPANY, ITS AGEINIS 02
P.O. BOX 189 REPRESENTATIVES.
NORTH READING, MA 01864 AUHIORIZED REPRESENTATIVE "—?
Aspsraeesr b JXOUWut.eeenswra
offim df1 +
600 Wea6Lwat swd
ati b%M4 021H
wMeRseoaajnlNi
Women'Cmpem daa Inomnaa Al SWU D MwmC berg
Name
Addfaw �` FD St
An yes m mieftoZ C ak Ift i f I l itm Type of ppviw 0010000
1.0 1 is s ospbyenvid 4. 01 es s smart asf saw sd i IL 0 Ns w aam madn
ampu! P -m tsdAw pors."4' I bw lid to , cause,
2.01 m s ob pmpeiaar ar paua- aped as de stleded Asa t 113 RamWdb$
eiip ad leave n eugbyea 11ae sicostrtafou bm a. p DesoU=
was dtr ip� svdm r am �d �. p Baodtep aftliiom
S. O Weseasoapaet-p fdilt
omwmsbvfUWcbdddr laozwc"npsisos'Ammons
3.0 I sobs alaloegwns agbaavolt rto(asemp"pwWKIL 11.13 P6m6ftnpis or adMdow
MYOK oft WeAsw NEW LIS%11(4%adwbsrao 12;lRmfnpdm
tsee taylCid)1 Qb wo6sM 13.0 Ode<.
om�iseettot requiei)
1 Ro i�
wi aftob"ebif *bommagasl�i�f�Ywatlr���&wri &iYale SOL
k'a�wge.sr awt eieoa a.r.r�Y1..dYMew iwt+o.is s.ws d`rm.�.u.../sitwti.r oesF paa4 i.lbvnieloa
r M dW*M~Ag kpnWAW wins'asyMsA*S AUW e.Jlr sv aspb.Wes asln.r Ab/+ q.wd jW8 j w
w\ �KarJ
pbltcy a of Somim Lid t (db'6 3� 3 or)2czS E, a Dmw
k6 Sill AMma V � /
Ate&s ow of da worker'agssodos paim aftrwn pw omft dw vow ma now mw wftaii6*m*
Pdkne a soam oovaW s gob,I seder Seaios 2SA ofUM a. 1S2 css lad loft.iopodda ofab d pensWw oft
flte uP a f1.Soo oo a+dkr osayen ioorbammoK s wd s"pa ma is de des oft srm wm owim and a flee
o(up a i2S0.oe a dtr agdm ds viobw. N abbed deb s copy of h mans mw be fbnvwM a do Office of
invadSWl=afdt MA aOvasOt veeiAadoa
IrvJ/r 11wrb ,q r6.f ab Pww�� ��anoes
l�ioeet 4 - UO l ,
ormwter A* Dr not sv*AN Ab err,of to awybsd AV C*oram e,QlefeL
Ctq or Toew hrs limm•
Issln Atfierlfy(dr&ones
I.Rced of Nadi 2.tlslidfq Dgmlmed 3.Cky/rows Cierk L Cem*d Iaepodor S.hndfi Isspeetor
d Oder
Costar tertar no"#I
bruem Geamd t-.we cat 152 m ptW all atpbyam b poviea` cOcs QwW �-- t
pmmast a thie treaeer a:sagdgre is dd.ad m-...avmy paaos im d•emviot of antler w der ay eo n bk%
«tip art or waimm"
As�11b'w it de6d as"s iedlvid.a�pmtaemhip. ►a•r7•r•d•u«other Ima edgy.or AW WO or mow
i.1oYa•eePiNr ad i.eltdi g tis>e�i repeemmeivat da dat m d or so
Otto 2W receivers P or Dear iqd emibr.mptitYit tl.wv�
ow.o da lourslrvittmtt mow tbes tbma Wmmemu and VA md"6m ,%ar�.ooat�t�ddor_
dads t been ofINO& r TM 009mg pa n a do m itsmoa.d•�«r•p•M a M b "
arse the 1�i«���tlarati al.t mttbeeaw dtmal .
�.cbWao 13%W"6)d n mire.d ooemy etde ar Md��s4 eW**100 tba io.smao or
raewd af.ree. w p•r�w mows".beahmee ar is anllyd hilt Y tb.aww.uwa�ltr■4
gpreart wN W�.t pmMead•.•4eiM•aldasp ate.st jtsa wllb rite htmtr.mw cwr•��•'��
Additias.lb►.ai0.dmqpW 15%jW0 own" dsm do eomutam•K•1�w aq dire poibipl.itWl i•�.•ti•�
am deco attp aamon t er�.pmtidr••dD•tit•mod d svide�oe of awepiilesw wi>i ds irau[ase.
raq irrmwte of thirdtapoer 1rraDew Pe•e•m'a tb boslneeit st4drr"
Appreaste
Pirw a We d*w ' aAttd.vit cota'pleteb►r tit►aed t de m bcm dW 8p*a YGw dertiom am6 if
sad plq�e» (►)dwtwdb 0*per)of
awergt,••ppb wb-�°' 1 (A)'ew•(r�.dme.tL 1.wiY4►Faeeemaip•W� m�D'ele omer the.�.
ummum1, Lialdllyr Q�%1 ma uic ar Mp am bWe
nmoobat«p�mea,aie set regaited a qnY watdtmr aot�s••d•u��
aatpioycae.a loft b mquiev ; B.advbd so this atsdsyltmtprbe mllmde d a the Daimmummal LiMtrid
Aacide m br ooedrsmlfrw Qf i aaesoe ca'mat• Ain ba wee to dO Md dw tdu aMdsvL The of l"A Ao.Y
be reruapd a tie cW crows torus tlat the ep undos is do p•d<ar 3mmei blot�•4•a•4 ad&o Dq r=M of
hdmraLi Aoriilatb seoaM> l.ve•w gdm ngp�dirt the htw ar i[yos aw regpieed>o abtatL.wottfmr.'
,,,p„ ,pia•ts aid d.Dagtih.ert o tetraber limel bde!k SdFirmed coe� iw alwid ast«thais
scuiwo.oel(odemeaisera'r >i�tu, .
cul ar Tws 0011111e
Phmn ba rise duo*a adM$vit i NOPI a ad putted lgilb. Tbr Dep�mwttiae p��•���•bottaa.
of the trtttlavit ftt yda p n cat io dw avert dw olio•otTrai gatim bo a ott.dct You tnt�for•ppi�•�
place be ee•e a m is tba per••e®'b�"'�"'m be aced m.rahraaa mmbar. >b adtlilia..a•apptid
that ague nbuis dipb pamiVHomw aPp&ad=i.."Sivas Yar,mead o*am*am adldn*kams�•
policy ish mmim(if uca my)•d ndpt'Jab Sia Add W the apptsam dlo.W writ."A beadon i._(dW err
tows."A appy ott4•odmit do br beeu Gd.W liy tttttatped«matld by do ck a Mm mW be povided Is for
appitart•podtMt.raW trfQdait i,as Art fir Arhus pedm«Aoaoa Anew amdsvit mmttba mied Dot aat
year When a lootanv.s�ef6eu i obeii�.ltoeee.«permit toot telmad a wy baaiat«coa®ooW vmaw
(i a.dot litx.�4« a bna la.vs der)Wd Dates i NOT required a aaatplate this aAeidmrt
Tba o®p dlm aftl*me wanx lira a*may"a dvmua A.i yoer 000pe -dn tmd abo.11 yom b.ve MY q.aAioma#
plena do mebedw d Aiv•m•eaL
7aa DcpWOmee aim mirploae d fk aambW
The Cammonwald o(Matmatrbosdto
Depu m d afb&mMd AWd=ft
Omer d bvad%§dM
600 Wuhinom Sind
B 016 MA 02111
TeL 0 617-727-4900 at 406 Of 1-MMASSAFB
Flat 0 617-727-7749
Reviud 5-2" WWW mmgOV/dA
PUKA PROMM DVANVUZNT
120 vamp en Oman R aae ooO
m`a»»s�oeos t:t ago
stAr.srw a. AL
DWC M.Of DM=AMDAVrt
is rsasdreo w*dot PWVW r dUK s4lk O4 I I I �t r a aa�dWoa
otfii ftp� ■be i"i Mwldslor dwaoowuodat rtrigr
0rs4f>taildl i abod oodamsp banduma mom
dqml filft r d— rlltio lm stift
loaalta�alFtidiiOr
• Dal.
M AM PUM CLaAI.Y)
L��� f
Nmr al AWlkrf
P'bsNaew�itaegr
Addm%CIV t SOW
The tow mew NOWN dot dabrts Am dr daooNo4 naovgkk%MA at ads
sk6"dWft a*WNW bo dt"W is a popaiy6&MW MA&,IM&Iposd